Terms & Conditions

35-Year Comprehensive Structural Warranty
Warranty Period
This warranty is valid for a period of 35 years from the date of project completion.
Conditions of Warranty

1. Proper Maintenance: The warranty is contingent upon the owner performing regular and necessary maintenance of the structure as recommended by Talwar Contractors. Failure to maintain the structure properly may void the warranty.

2. Prompt Notification: The owner must notify Talwar Contractors in writing of any defects or issues covered by this warranty within 30 days of discovery.

3. Access for Inspection: The owner must provide Talwar Contractors or its authorized representatives access to the property to inspect and assess the reported defects.

4. Repairs and Modifications: Any repairs or modifications to the covered structural elements must be performed by Talwar Contractors or its authorized representatives. Unauthorized repairs or modifications may void the warranty.

5. Normal Wear and Tear: This warranty does not cover normal wear and tear, aesthetic issues, or cosmetic damage that does not affect the structural integrity of the building.

6. Acts of Nature: This warranty does not cover damage caused by natural disasters, including but not limited to earthquakes, floods, hurricanes, tornadoes, and other extreme weather conditions.

7. Usage Changes: Any changes in the usage or occupancy of the building that result in increased structural loads or stresses not accounted for in the original design may void the warranty.

Exclusions
This warranty does not cover:

• Non-structural elements such as drywall, paint, flooring, and other finishes.

• Damage caused by unauthorized alterations, misuse, or negligence by the owner or third parties.

• Any defects or issues not reported within the warranty period.

• Consequential or incidental damages arising from structural defects.
   

• Warranty Claims

• To make a warranty claim, the owner must:

• Submit a written notification to Talwar Contractors detailing the nature of the defect and the date it was discovered.

• Provide access to the property for inspection by Talwar Contractors or its authorized representatives.

• Allow Talwar Contractors to perform necessary repairs or corrective actions as deemed appropriate under the terms of this warranty.
  
  Commitment to Speed and Quality:
  At Talwar Contractors, we are dedicated to delivering your construction projects with exceptional speed and quality. Our terms and conditions outline the responsibilities and expectations of both Talwar Contractors and our clients to ensure a smooth and efficient construction process.
  1. Delayed Decisions

• Client Responsibility: Clients are expected to make timely decisions regarding project details, approvals, and changes.

• Contractor Responsibility: Talwar Contractors will maintain open communication with clients to facilitate prompt decision-making.
  2. Frequent Changes

• Client Responsibility: Clients should provide thorough planning and clear specifications from the outset to minimize the need for continuous changes in design, scope, or specifications.

• Contractor Responsibility: Talwar Contractors will work closely with clients to ensure all initial plans and specifications are detailed and agreed upon before project commencement.
  3. Incomplete Specifications

• Client Responsibility: Clients must ensure that all project specifications are complete and clear to avoid misunderstandings and delays.

• Contractor Responsibility: Talwar Contractors will review and verify the completeness and clarity of all project specifications provided by the client.
  4. Payment Delays

• Client Responsibility: Clients are required to make timely payments as per the agreed payment schedule to maintain smooth cash flow for the project.

• Contractor Responsibility: Talwar Contractors will provide detailed invoicing and will work closely with clients to address any payment-related queries or issues promptly.
  5. Budget Constraints

• Client Responsibility: Clients should provide detailed budgeting information and ensure that funds are available to prevent disruptions due to budget constraints.

• Contractor Responsibility: Talwar Contractors will offer detailed budgeting and cost management services to help clients plan and allocate resources effectively.
  6. Approval Delays

• Client Responsibility: Clients must streamline their internal approval processes for materials, designs, and project milestones.

• Contractor Responsibility: Talwar Contractors will coordinate with clients to ensure all necessary approvals are obtained in a timely manner.
  7. Inadequate Site Access

• Client Responsibility: Clients should coordinate with Talwar Contractors to ensure timely access to construction sites and necessary utilities.

• Contractor Responsibility: Talwar Contractors will work with clients to plan and facilitate site access and utility availability as required for the project.
  General Provisions

• Force Majeure: Neither party shall be liable for any delays or failures in performance due to circumstances beyond their reasonable control, including but not limited to acts of God, natural disasters, or governmental actions.

• Dispute Resolution: Any disputes arising out of or in connection with these terms and conditions shall be resolved through mutual negotiation. If a resolution cannot be reached, the dispute shall be referred to arbitration in accordance with the applicable laws.

• Amendments: Talwar Contractors reserves the right to amend these terms and conditions as necessary. Clients will be notified of any changes, and continued engagement with our services will constitute acceptance of the revised terms.

• Governing Law: These terms and conditions shall be governed by and construed in accordance with the laws of India.

Terms & Conditions - the basics
Changes to Terms and Conditions
Talwar Contractors reserves the right to modify these terms and conditions at any time. Any changes will be posted on this page, and your continued use of the website signifies your acceptance of such changes.
Limitation of Liability
Talwar Contractors shall not be liable for any damages arising out of or in connection with the use of this website. This limitation of liability applies to direct, indirect, consequential, special, punitive, or other damages you may suffer, as well as damages for loss of profits, business interruption, or loss of data or information.
Governing Law
These terms and conditions are governed by and construed in accordance with the laws of India. Any disputes arising from or related to these terms and conditions shall be resolved in the courts of Delhi, India.
General Terms

1. Use of the Website: The content of this website is for your general information and use only. It is subject to change without notice.

2. Intellectual Property: All content on this website, including but not limited to text, graphics, logos, and images, is the property of Talwar Contractors and is protected by intellectual property laws.

3. User Conduct: You agree to use this website only for lawful purposes. You are prohibited from using this website in a way that could damage, disable, overburden, or impair the website or interfere with any other party's use and enjoyment of the website.